Legal Opinion
Havens Steel Co. v. Randolph Engineering Co.
District Court, W.D. Missouri
Decided May 7, 1985No. 80-0898-CV-W-0PublishedCited by 18 opinions
1Opinion of the Court
MEMORANDUM OPINION AND JUDGMENT
ROSS T. ROBERTS, District Judge.
Plaintiff Havens Steel Company (“Havens”) seeks damages allegedly incurred as the result of defective or deviate work performed under a construction subcontract between it and defendant Randolph Engineering Company (“Randolph”). Randolph counterclaims for various damages it believes it suffered by reason of job interference, work delays and uncompensated extra work. Jurisdiction is based upon diversity of citizenship.
The matter has been tried to the court. For the reasons which follow I render judgment in Randolph’s favor on both…
2Cases cited64 opinions
- United States v. Blair Ex Rel. Roanoke Marble & Granite Co.Supreme Court of the United States · 1944
- J. D. Hedin Construction Company, Inc., for Its Own Use and for the Use of Fischbach & Moore, Its Sub-Contractor v. The United StatesUnited States Court of Claims · 1965
- James A. Boyajian, Assignee of Triumph Manufacturing Company, Bankrupt v. The United StatesUnited States Court of Claims · 1970
- Zenith Radio Corp. v. Matsushita Electric Industrial Co.District Court, E.D. Pennsylvania · 1980
- United States v. Howard P. Foley Co.Supreme Court of the United States · 1946
59 more not listed; retrieve them via the Exa API.
3Cited by18 opinions
- Business Men's Assurance Co. of America v. GrahamMissouri Court of Appeals · 1994
- AROK Construction Co. v. Indian Construction ServicesCourt of Appeals of Arizona · 1993
- Claris, Ltd. v. Hotel Dev. Servs., L.L.C.Ohio Court of Appeals · 2018
- Southern St. Masonry v. JA Jones Const.Supreme Court of Louisiana · 1987
- Rosebud Sioux Tribe v. A & P Steel, Inc.Court of Appeals for the Eighth Circuit · 1989
13 more not listed; retrieve them via the Exa API.