Morris Mechanical Enterprises, Inc. v. United States

OPINION

SPECTOR, Judge:

On November 17, 1982, it was held in a decision on the merits of this case that plaintiff was:

entitled to an extension of time sufficient to permit it to complete its work after installation of the chiller by another contractor, and there has been no “refusal or failure to complete the work within the specified time,” when it is properly extended for circumstances beyond plaintiff’s control. It follows that defendant is not entitled to withhold the sum of $23,100 in liquidated damages from amounts otherwise due plaintiff under its contract and that judgment in that…