Northern Clearing, Inc. v. Larson-Juhl, Inc.

Northern Clearing, Inc., Plaintiff-Respondent,

v.

Larson-Juhl, Inc., Defendant-Appellant.

No. 04-0010.

Court of Appeals of Wisconsin.

Opinion Filed: September 21, 2004.

Before Cane, C.J., Hoover, P.J., and Peterson, J.

¶1 PER CURIAM.

Larson-Juhl, Inc., appeals a judgment awarding $211,037.66 damages, plus costs and prejudgment interest, to Northern Clearing, Inc. Larson-Juhl argues: (1) Northern's subcontract prohibited damages for delay; (2) the trial court erroneously awarded Northern damages on a theory of quantum meruit; (3) the court applied an erroneous measure of damages and miscalculated…