W. Wright, Inc. v. Korshoj Corp.

Brodkey, J'.

This is an appeal from the verdict of a jury, and judgment entered thereon, by the District Court for Douglas County, upholding the claim of a subcon tractor for damages against the prime contractor for additional expenses incurred by the subcontractor as a result of suspension of work on a contract between the U.S. Government and the prime contractor. We affirm in part, and in part reverse and remand with directions.

In May 1972, the United States Government, through the Corps of Engineers, awarded a general contract to Korshoj Corporation (“Korshoj”), the defendant and appellant…