Legal Opinion
Albany Specialties, Inc. v. Shenendehowa Central School District
Appellate Division of the Supreme Court of the State of New York
Decided July 10, 2003PublishedCited by 12 opinions
1Opinion of the CourtMugglin, J.
Appeal from an order of the Supreme Court (Ferradino, J.), entered September 4, 2002 in Saratoga County, which granted defendant’s motion for summary judgment dismissing the complaint.
During plaintiff’s performance of a multiyear contract to reconstruct the heating, ventilating and air-conditioning systems at one of defendant’s school buildings, defendant notified plaintiff that it intended to back charge plaintiff a portion of unanticipated temporary heating costs allegedly caused by plaintiff’s delay of the project. Disputing the back charge, plaintiff requested that the project architect…
2Cases cited5 opinions
- Gibeault v. Home Insurance CompanyAppellate Division of the Supreme Court of the State of New York · 1995
- Prote Contracting Co. v. Board of EducationAppellate Division of the Supreme Court of the State of New York · 1993
- Board of Education of the Union-Endicott Central School District v. New York State Public Employment Relations BoardAppellate Division of the Supreme Court of the State of New York · 1998
- Bader v. Board of EducationAppellate Division of the Supreme Court of the State of New York · 1995
- Eastern Environmental Services of the Northeast, Inc. v. Brunswick Central School DistrictAppellate Division of the Supreme Court of the State of New York · 1992
3Cited by12 opinions
- Hahn Automotive Warehouse, Inc. v. American Zurich InsuranceNew York Court of Appeals · 2012
- Kingsley Arms, Inc. v. Copake-Taconic Hills Central School DistrictAppellate Division of the Supreme Court of the State of New York · 2004
- Kyer v. Ravena-Coeymans-Selkirk Central School DistrictAppellate Division of the Supreme Court of the State of New York · 2016
- Elia v. Highland Central School DistrictAppellate Division of the Supreme Court of the State of New York · 2010
- TIG Insurance v. Newmont Mining Corp.District Court, S.D. New York · 2005
7 more not listed; retrieve them via the Exa API.