Osceola County v. BUMBLE BEE CONST.

479 So.2d 310 (1985)

OSCEOLA COUNTY, Florida, Appellant,

v.

BUMBLE BEE CONSTRUCTION, INC., etc., Appellee.

No. 85-10.

District Court of Appeal of Florida, Fifth District.

December 12, 1985.

John B. Ritch, Kissimmee, for appellant.

Leslie King O'Neal of Markel, McDonough & O'Neal, Orlando, for appellee.

SHARP, Judge.

Osceola County appeals from a judgment entered against it involving a construction contract. It argues the trial court erred in denying its claim for liquidated damages under the contract, in awarding prejudgment interest, and in failing to grant its motion to dismiss. We find no error as…