Pal Construction Corp. v. Leonard B. Hebert, Jr. & Co.

RLEES, Judge.

Plaintiff, Pal Construction Corporation (Pal), filed suit against defendant, Leonard B. Hebert, Jr. & Company, Inc. (Hebert), for damages in the amount of $184,770.72 arising from defendant’s alleged breach of a construction subcontract between the parties. Defendant filed a motion for partial summary judgment seeking to have certain claims of Pal dismissed. From the trial court judgment dismissing all of its claims for delay damages, plaintiff appeals.

On April 20, 1982, Hebert entered into a subcontract with Pal to erect structural steel on a project known as the “SA2 Silo and…