Legal Opinion
Mw Builders, Inc. v. United States
United States Court of Federal Claims
Decided October 18, 2017No. 13-1023 CPublishedCited by 7 opinions
1Opinion of the Court
Anti-Deficiency Act, 31 U.S.C. § 1350; Breach of Contract; Contract Disputes Act, 41 U.S.C. §§ 7101-7109; Counterclaims, 28 U.S.C. § 2508; False Claims Act, 31 U.S.C. §§ 3729-3733; Federal Acquisition Regulation, 48 C.F.R. §§ 52.211-12 (Liquidated Damages), 52.242-14 (Suspension of Work), 52.’249-10 (Contract Default); Good Faith and Fair Dealing; Special Plea In Fraud, 28 U.S.C. § 2514; Tucker Act Jurisdiction, 28 U.S.C. § 1491; Unreasonable Delay; Waiver.
POST-TRIAL MEMORANDUM OPINION AND FINAL ORDER 1
SUSAN G. BRADEN, Chief Judge
This case concerns the United States Army Corps of Engineers…
2Cases cited64 opinions
- Lujan v. Defenders of WildlifeSupreme Court of the United States · 1992
- Warth v. SeldinSupreme Court of the United States · 1975
- Friends of the Earth, Inc. v. Laidlaw Environmental Services (TOC), Inc.Supreme Court of the United States · 2000
- Universal Health Services, Inc. v. United States ex rel. EscobarSupreme Court of the United States · 2016
- South Corporation and Seal Fleet, Inc. v. The United StatesCourt of Appeals for the Federal Circuit · 1982
59 more not listed; retrieve them via the Exa API.
3Cited by7 opinions
- Jindal Builders & Restoration Corp. v. Cincinnati Metro. Hous. Auth.Ohio Court of Appeals · 2020
- Information Systems & Networks Corporation v. United StatesUnited States Court of Federal Claims · 2020
- Lcc-Mzt Team IV v. United StatesUnited States Court of Federal Claims · 2021
- Lw Construction of Charleston, LLC v. United StatesUnited States Court of Federal Claims · 2018
- Lw Construction of Charleston, LLC v. United StatesUnited States Court of Federal Claims · 2018
2 more not listed; retrieve them via the Exa API.