Welch Construction & Excavating, LLC v. Duong

McEVERS, Justice.

[¶ 1] Linh Due Duong, doing business as Classy Nails, appeals from a judgment entered after a bench trial awarding Welch Construction & Excavating, LLC, $30,825, plus interest, for the balance due on a construction contract. We conclude the district court did not clearly err in finding: (1) the parties did not orally contract for a specific completion date for the construction project;- (2) Welch Construction did not unreasonably delay completion of the project; and (3) Duong failed to establish his damages for costs to repair and lost profits for Welch Construction’s claimed…