Caddell Construction Co. v. United States

*408 OPINION & ORDER

FUTEY, Judge.

This government contract case is before the court following a trial on liability and damages. Plaintiff claims, on behalf of its steel fabrication subcontractor, that defendant provided structural steel drawings that allegedly contained conflicts, errors, omissions, and/or inadequate details. Plaintiff maintains that the purportedly defective drawings resulted in a delay and additional costs. Plaintiff, therefore, requests an equitable adjustment of $2,782,149.52. Defendant argues that the designs were not defective and that plaintiff, not defendant, was the cause…