Legal Opinion
Fred A. Arnold, Inc. v. United States
United States Court of Claims
Decided August 6, 1991No. 578-86 CPublished
1Opinion of the Court
OPINION
WIESE, Judge.
I
In an earlier opinion in this case, this court examined the correctness, under the standards of review prescribed by the Wunderlich Act, 41 U.S.C. §§ 321-322 (1988), of a decision of the Armed Services Board of Contract Appeals. The decision in question had denied substantially all of the contractor’s (plaintiff’s) claims for equitable adjustments in contract price and time as well as the Government’s claim for liquidated damages. We affirmed the board’s denial of the contractor’s claims and reversed its denial of the Government’s claim. Fred A. Arnold, Inc. v. United…
2Cases cited11 opinions
- New Colonial Ice Co. v. HelveringSupreme Court of the United States · 1934
- S&E Contractors, Inc. v. United StatesSupreme Court of the United States · 1972
- Stein Bros. Mfg. Co. v. United StatesUnited States Court of Claims · 1963
- Janet L. Wallace v. Department of the Air ForceCourt of Appeals for the Federal Circuit · 1989
- Ernest Samuel Nossen and E. S. Nossen Laboratories, Inc. v. The United StatesUnited States Court of Claims · 1969
6 more not listed; retrieve them via the Exa API.