Legal Opinion
WDF Inc. v. Trustees of Columbia Univ. in the City of N.Y.
Appellate Division of the Supreme Court of the State of New York
Decided December 14, 2017No. 651250/16 5237 5236PublishedCited by 6 opinions
1Opinion of the Court
Orders, Supreme Court, New York County (Barry R. Os-trager, J.), entered November 15, 2016, which, to the extent appealed from as limited by the briefs, granted defendants’ motions to dismiss the second cause of action as to all claims for costs incurred due to delays caused by a stop work order and the third and fourth causes of action in their entirety, unanimously affirmed, with costs.
The subcontract entered into by plaintiff contained a no-damages-for-delay provision. Such a provision “is valid and enforceable and is not contrary to public policy” where, as here, “the clause and the…
2Cases cited2 opinions
- Leon v. MartinezNew York Court of Appeals · 1994
- Corinno Civetta Construction Corp. v. City of New YorkNew York Court of Appeals · 1986
3Cited by6 opinions
- Federated Fire Protection Sys. Corp. v. 56 Leonard St., LLCAppellate Division of the Supreme Court of the State of New York · 2020
- Federated Fire Protection Sys. Corp. v. 56 Leonard St., LLCAppellate Division of the Supreme Court of the State of New York · 2020
- Five Star Elec. Corp. v. Silverite Constr. Co., Inc.Appellate Division of the Supreme Court of the State of New York · 2023
- Five Star Elec. Corp. v. Silverite Constr. Co., Inc.Appellate Division of the Supreme Court of the State of New York · 2023
- AWL Indus., Inc. v. New York City Hous. Auth.Appellate Division of the Supreme Court of the State of New York · 2025
1 more not listed; retrieve them via the Exa API.