Legal Opinion
Crosswell v. Arten Construction Co.
Court of Appeals of Georgia
Decided October 31, 1979No. 58732PublishedCited by 12 opinions
1Opinion of the Court
McMurray, Presiding Judge.
This is an action for a breach of a construction contract predicated upon a June 26, 1976, agreement whereby Arten Construction Company agreed to construct a building for Crosswell (Brandon Hall faculty residence building). The contract made time of the essence and provided that the project be commenced on or before August 15, 1976, and be completed 100 days after commencement. However, Crosswell instructed Arten not to begin construction and considerable delay ensued. When Crosswell became ready to commence the project, Arten declined to construct the building at…
2Cases cited21 opinions
- Dill v. StateSupreme Court of Georgia · 1966
- Martin v. BaldwinSupreme Court of Georgia · 1959
- Shouse v. StateSupreme Court of Georgia · 1974
- Knudsen v. Duffee-Freeman, Inc.Court of Appeals of Georgia · 1957
- Crankshaw v. Stanley Homes, Inc.Court of Appeals of Georgia · 1974
16 more not listed; retrieve them via the Exa API.
3Cited by12 opinions
- Atlanta Recycled Fiber Co. v. Tri-Cities Steel Co.Court of Appeals of Georgia · 1979
- Raybestos-Manhattan, Inc. v. FriedmanCourt of Appeals of Georgia · 1981
- Williams v. StateCourt of Appeals of Georgia · 1980
- Franklin v. Demico, Inc.Court of Appeals of Georgia · 1986
- Thico Plan, Inc. v. AshkoutiCourt of Appeals of Georgia · 1984
7 more not listed; retrieve them via the Exa API.