Gemma Construction Co. v. City of New York
Appellate Division of the Supreme Court of the State of New York
1Opinion of the Court
Order, Supreme *452Court, New York County (Jane Solomon, J.), entered May 2, 1997, which denied defendant City of New York’s motion for partial summary judgment dismissing plaintiff’s first cause of action, unanimously affirmed, without costs.
In its first cause of action, plaintiff contractor seeks to recover damages of $1,457,049.38 for delay in completing work under its contract with the City. The second cause of action, which seeks to recover a $35,000 balance alleged to be due under the contract, is not at issue. An internal memorandum from defendant’s project manager specifies three periods…
2Cases cited14 opinions
- Corinno Civetta Construction Corp. v. City of New YorkNew York Court of Appeals · 1986
- Laba v. CareyNew York Court of Appeals · 1971
- Corhill Corp. v. S. D. Plants, Inc.New York Court of Appeals · 1961
- Spaulding v. BenenatiNew York Court of Appeals · 1982
- Buckley & Co. v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 1986
9 more not listed; retrieve them via the Exa API.
3Cited by8 opinions
- FCI Group, Inc. v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 2008
- CAB Associates v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 2006
- Visconti Corp. v. LaBarge Bros.Appellate Division of the Supreme Court of the State of New York · 2000
- Graciano Corp. v. Lanmark Group, Inc.Appellate Division of the Supreme Court of the State of New York · 2023
- Graciano Corp. v. Lanmark Group, Inc.Appellate Division of the Supreme Court of the State of New York · 2023
3 more not listed; retrieve them via the Exa API.