Young Electrical Contractors, Inc. v. Dustin Construction, Inc.

Appellant, Young Electrical Contractors, Inc. (“Young”), entered into a subcontractor agreement with appellee, Dustin Construction, Inc. (“Dustin”) to perform all required electrical work for a prime contract Dustin entered into with George Mason University in Virginia. Due to a number of delays in the project, Young was unable to meet the agreed-upon date for substantial completion of the work. As a result, Young experienced a number of cost overruns and sought payment for those overages via a number of change requests. When Young did not receive those payments from the university via…