Penzel Construction Company, Inc. v. Jackson R-2 School District

In the Missouri Court of Appeals Eastern District DIVISION THREE PENZEL CONSTRUCTION COMPANY, ) No. ED108821 INC., ) Respondent, ) Appeal from the Circuit Court ) of Cape Girardeau County vs. ) ) Honorable Benjamin F. Lewis JACKSON R-2 SCHOOL DISTRICT, ) ) Appellant. ) FILED: July 20, 2021 Introduction The parties to this appeal appear for a second time before this Court in a contract dispute involving substantial delays and cost overruns in connection with a construction project for the renovation and addition to the Jackson High School campus. The Jackson R-2 School District (the…