Legal Opinion
Anthony P. Miller, Inc. v. Wilmington Housing Authority
District Court, D. Delaware
Decided November 3, 1959No. Civ. A. 1739PublishedCited by 10 opinions
1Opinion of the Court
LAYTON, District Judge.
These are cross motions for summary judgment arising out of an action 1 to recover monies allegedly wrongfully withheld under a certain construction contract between Anthony P. Miller, Inc. (Miller), plaintiff, and Wilmington Housing Authority, the defendant. 2
Miller, the successful bidder on the prime contract, commenced construction of a low rent housing project in this area on or about May 26, 1952. However, the course of the work was plagued by numerous delays including inclement weather and, particularly, strikes, and was not finished until long after the specified…
2Cases cited13 opinions
- Doehler Metal Furniture Co. v. United StatesCourt of Appeals for the Second Circuit · 1945
- United States v. WunderlichSupreme Court of the United States · 1951
- Traylor v. Black, Sivalls & Bryson, Inc.Court of Appeals for the Eighth Circuit · 1951
- Terminal Construction Corp. v. Bergen County Hackensack River Sanitary Sewer District AuthoritySupreme Court of New Jersey · 1955
- United States v. SmithSupreme Court of the United States · 1921
8 more not listed; retrieve them via the Exa API.
3Cited by10 opinions
- Ruvolo v. American Casualty Co.Supreme Court of New Jersey · 1963
- Autoridad Sobre Hogares v. Tribunal Superior de Puerto RicoSupreme Court of Puerto Rico · 1961
- Limestone Realty Co. v. Town & Country Fine Furniture & Carpeting, Inc.Court of Chancery of Delaware · 1969
- Wilson Contracting Co. v. StateSupreme Court of Delaware · 1966
- Collison v. DeisemCourt of Chancery of Delaware · 1970
5 more not listed; retrieve them via the Exa API.