Grand Rapids Asphalt Paving Co. v. City of Wyoming

This appeal involves an action by plaintiffs on a road construction contract entered into with defendant, City of Wyoming, to recover $5,625 withheld from plaintiffs by defendant as liquidated damages for failure of plaintiffs to timely complete performance under the contract. The case was tried in the Kent County Circuit Court without a jury, and judgment was entered for plaintiffs in the amount of money withheld as liquidated damages by defendant plus interest from July 11, 1966, to date of trial, May 18, 1968, and a judgment of no cause of action, not relevant to this appeal, was entered…