Legal Opinion
S.N. Tannor, Inc. v. A.F.C. Enterprises, Inc.
Appellate Division of the Supreme Court of the State of New York
Decided October 19, 2000PublishedCited by 5 opinions
1Opinion of the Court
Order, Supreme Court, New York County (Charles Ramos, J.), entered June 22, 1999, which, to the extent appealed from as limited by the brief, granted the motion of defendant A.F.C. Enterprises, Inc. for summary judgment dismissing the complaint as against it, unanimously affirmed, without costs.
Plaintiff S.N. Tannor, Inc., a subcontractor on a public works construction project for which defendant A.F.C. Enterprises was the general contractor, sues to recover damages for extra work and delays allegedly occasioned by the conduct of A.F.C. However, the subcontract between S.N. Tannor and A.F.C.…
2Cases cited3 opinions
- Corinno Civetta Construction Corp. v. City of New YorkNew York Court of Appeals · 1986
- Buckley & Co. v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 1986
- Martin Mechanical Corp. v. P. J. Carlin Construction Co.Appellate Division of the Supreme Court of the State of New York · 1987
3Cited by5 opinions
- Travelers Casualty & Surety Co. v. Dormitory Authority-StateDistrict Court, S.D. New York · 2010
- Blue Water Environmental, Inc. v. Incorporated Village of BayvilleAppellate Division of the Supreme Court of the State of New York · 2007
- Commercial Electrical Contractors, Inc. v. Pavarini Construction Co.Appellate Division of the Supreme Court of the State of New York · 2008
- Bat- Jac Contracting, Inc. v. New York City Housing AuthorityAppellate Division of the Supreme Court of the State of New York · 2003
- T.J.D. Construction Co. v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 2002