Lowry Electric Co. v. State

OPINION

Montana, C.J.

The Claimant, Lowry Electric Company, brought this claim seeking $122,487.31 in damages due to delays and other problems Claimant encountered in the performance of a construction contract with the Respondent’s Capital Development Board (hereinafter referred to as “CDB”). The cause was consolidated for trial purposes only with claims of Guarantee Electrical Company, Lippert Brick Contracting, and K & S Associates, Inc.

The facts of the case are sufficiently set out in separate opinions of this Court relating to the claims of the joined Claimants so that only those facts…