Mack v. State
New York Court of Claims
1Opinion of the CourtSmith, J.
This claim is for damages alleged by claimants to have been sustained by them as the results of delays occasioned by the fault of the state in the performance of the work of three several contracts which claimants had with the state.
*87The contracts were for the installation of certain electrical work to be installed in buildings to be erected by the state at Letchworth Village, a state institution.
Claimants claim that the state unreasonably and negligently delayed getting its buildings in readiness for the installation of the electrical work and equipment contracted to be done by the claimants…
Also in this document: Concurrence.
2Cases cited7 opinions
- Mansfield v. . N.Y.C. H.R.R.R. Co.New York Court of Appeals · 1886
- Del Genovese v. Third Avenue RailroadAppellate Division of the Supreme Court of the State of New York · 1897
- Allamon v. Mayor of AlbanyNew York Supreme Court · 1864
- M. L. Ryder Building Co. v. City of AlbanyAppellate Division of the Supreme Court of the State of New York · 1919
- W. L. Waples Co. v. StateAppellate Division of the Supreme Court of the State of New York · 1917
2 more not listed; retrieve them via the Exa API.
3Cited by14 opinions
- Kalisch-Jarcho, Inc. v. City of New YorkNew York Court of Appeals · 1983
- Corinno Civetta Construction Corp. v. City of New YorkNew York Court of Appeals · 1986
- Siefford v. Housing Auth. of City of HumboldtNebraska Supreme Court · 1974
- A. Kaplen & Son, Ltd. v. Housing Authority of PassaicNew Jersey Superior Court Appellate Division · 1956
- Humphreys v. J. B. Michael & Co.Court of Appeals of Kentucky (pre-1976) · 1960
9 more not listed; retrieve them via the Exa API.