Legal Opinion
M. Farbman & Sons, Inc. v. New York City Health & Hospitals Corp.
Appellate Division of the Supreme Court of the State of New York
Decided July 14, 1983PublishedCited by 2 opinions
1Opinion of the Court
OPINION OF THE COURT
Ross, J.
On November 25, 1977, M. Farbman & Sons, Inc. (petitioner) entered into a contract with the New York City Health and Hospitals Corporation (HHC) for the installation of plumbing, as part of the renovation of “K” Building *577at Harlem Hospital, located in Manhattan. The original contract price was $273,421. However, a change order raised that amount to $336,063. The contract completion date was May 18, 1979; but, petitioner did not actually finish until November 12, 1980. Petitioner contends this delay was the fault of HHC. As a result of the delay, petitioner claims…
2Cases cited6 opinions
- John P. v. WhalenNew York Court of Appeals · 1981
- City of New York v. FriedbergAppellate Division of the Supreme Court of the State of New York · 1978
- D'Alessandro v. Unemployment Insurance Appeal BoardAppellate Division of the Supreme Court of the State of New York · 1977
- Arzuaga v. New York City Transit AuthorityAppellate Division of the Supreme Court of the State of New York · 1979
- John T. Brady & Co. v. City of New YorkAppellate Division of the Supreme Court of the State of New York · 1982
1 more not listed; retrieve them via the Exa API.
3Cited by2 opinions
- Cornell University v. City of New York Police DepartmentAppellate Division of the Supreme Court of the State of New York · 1989
- Billups v. SantucciAppellate Division of the Supreme Court of the State of New York · 1989