Legal Opinion
Residential Carpentry Corp. of Florida, Inc. v. Kister Wood Products
Circuit Court for the Judicial Circuits of Florida
Decided April 9, 1990No. Case No. 86-0303-Ca-01-WLBPublished
1Opinion of the Court
OPINION OF THE COURT
WILLIAM L. BLACKWELL, Circuit Judge.
FINAL JUDGMENT
This case was tried for six days to the Court as fact-finder. Residential Carpentry Corporation of Florida, Inc. (Residential) contracted with Defendant, Kister Wood Products, Inc. (Kister) to install in the *187Ritz-Carlton Hotel in Naples, Florida most of the finished woodwork and millwork which Kister had contracted to provide Metric Constructors, Inc. (Metric), the general contractor on this construction project. Residential sued Kister contending Kister unreasonably delayed performance and inadequately performed its…
2Cases cited6 opinions
- S. Leo Harmonay, Inc. v. Binks Manufacturing Co.District Court, S.D. New York · 1984
- Southern Gulf Utilities, Inc. v. Boca Ciega Sanitary DistrictDistrict Court of Appeal of Florida · 1970
- CA Davis, Inc. v. City of MiamiDistrict Court of Appeal of Florida · 1981
- Bumby & Stimpson, Inc. v. Peninsula Utilities Corp.District Court of Appeal of Florida · 1964
- McIntire v. Green-Tree Communities, Inc.District Court of Appeal of Florida · 1975
1 more not listed; retrieve them via the Exa API.