High Voltage Systems, Inc. v. Department of Highways

RULEY, JUDGE:

The claimant and respondent entered into a contract in September *51973 for the installation of traffic signals in Clarksburg. There were two projects in the contract designated as T-4009(l) and F-282(76). The respondent gave the claimant notice to proceed in October 1973, at which time claimant negotiated with suppliers for the various materials needed for the projects. Construction of the projects began on July 23, 1974, with a scheduled completion date of December 30, 1974. Completion of construction occurred in June 1975. Claimant contends that problems which occurred during…