Legal Opinion
North Harris County Junior College District v. Fleetwood Construction Co.
Court of Appeals of Texas
Decided June 25, 1980No. B2177PublishedCited by 27 opinions
1Opinion of the Court
SALAZAR, Justice.
This is an appeal from a judgment against North Harris County Junior College awarding to contractor Fleetwood withheld retainage, delay damages, and compensation for extra work performed because of a concealed condition. Gregory-Edwards, one of the subcontractors, also appeals from that part of the judgment which denies it attorney’s fees from Fleetwood. We affirm the judgment of the trial court.
Statement of the Case
On December 13, 1973, Fleetwood submitted his bid on construction of a portion of Phase I of the North Harris County Junior College project, including…
2Cases cited5 opinions
- Thomas Lonergan v. San Antonio Trust Co.Texas Supreme Court · 1907
- Board of Regents of the University of Texas v. S & G Construction Co.Court of Appeals of Texas · 1975
- Wisznia v. WilcoxCourt of Appeals of Texas · 1969
- City of Houston v. R. F. Ball Construction Co.Court of Appeals of Texas · 1978
- Anderson Development Corp. v. Coastal States Crude Gathering Co.Court of Appeals of Texas · 1976
3Cited by27 opinions
- Interstate Contracting Corp. v. City of DallasTexas Supreme Court · 2004
- Gulf Liquids New River Project, LLC v. Gulsby Engineering, Inc., Texas Court of Appeals, 1st District (Houston)2011
- Alamo Community College District v. Browning Construction Co., Texas Court of Appeals, 4th District (San Antonio)2004
- Shintech Inc. v. Group Constructors, Inc.Court of Appeals of Texas · 1985
- Tribble & Stephens Co. v. Consolidated Services, Inc., Texas Court of Appeals, 4th District (San Antonio)1987
22 more not listed; retrieve them via the Exa API.