Legal Opinion
All Seasons Construction, Inc. v. Mansfield Housing Authority
Louisiana Court of Appeal
Decided January 25, 2006No. 40,490-CAPublishedCited by 2 opinions
1Opinion of the CourtStewart, J.
hAU Seasons Construction, Inc. (“ASC”) filed suit against the Mansfield Housing Authority (“MHA”) to recover $22,200 withheld as liquidated damages under a construction contract between the two parties. MHA asserted a reconventional demand seeking damages, costs, and attorney fees for ASC’s alleged failure to perform its contractual obligations. The pertinent issue was the date of substantial completion of the project, which the trial *415court resolved in ASC’s favor. MHA appealed the judgment ordering it to pay damages. Finding no manifest error, we affirm.
FACTS
The parties entered a contract on…
Also in this document: Concurrence.
2Cases cited3 opinions
- Rosell v. EscoSupreme Court of Louisiana · 1989
- O & M Construction, Inc. v. State, Division of AdministrationLouisiana Court of Appeal · 1991
- Utley-James of La., Inc. v. State, Div. of Admin.Louisiana Court of Appeal · 1995
3Cited by2 opinions
- Urban's Ceramic Tile, Inc. v. McLainLouisiana Court of Appeal · 2013
- Central Electric Co. of Alexandria v. England Economic & Industrial Development DistrictLouisiana Court of Appeal · 2012