Legal Opinion
Gruschus v. CR Davis Contracting Company
New Mexico Supreme Court
Decided September 7, 1965No. 7642PublishedCited by 21 opinions
1Opinion of the Court
NOBLE, Justice.
Jack Adams Construction Company, Inc., (hereinafter termed Adams), primé contractor for the construction of some ten miles of four-lane concrete highway, sued its subcontractor, C. R. Davis Contracting Company, Inc., (hereinafter termed Davis)1, for damages occasioned by Davis’ failure to complete its subcontract within the time required by the contract. Davis counterclaimed for damages resulting from Adams’ fkilure to prepare the cement treated base within the tolerances required by the highway department specifications, and for a balance claimed to be due under the…
2Cases cited16 opinions
- Fitzgerald v. FitzgeraldNew Mexico Supreme Court · 1962
- Fanderlik-Locke Co. v. United StatesCourt of Appeals for the Tenth Circuit · 1960
- United States v. Henke Const. Co.Court of Appeals for the Eighth Circuit · 1946
- Banta v. Stamford Motor Co.Supreme Court of Connecticut · 1914
- Zengerle v. the Commonwealth Insurance Co. of NYNew Mexico Supreme Court · 1958
11 more not listed; retrieve them via the Exa API.
3Cited by21 opinions
- McCasland v. PratherNew Mexico Court of Appeals · 1978
- United States ex rel. C.J.C., Inc. v. Western States Mechanical Contractors, Inc.Court of Appeals for the Tenth Circuit · 1987
- Gallegos v. WilkersonNew Mexico Supreme Court · 1968
- Construction Contracting & Management, Inc. v. McConnellNew Mexico Supreme Court · 1991
- The United States of America, for the Use of C.J.C., Inc., a New Mexico Corporation v. Western States Mechanical Contractors, Inc., a New Mexico Corporation Commercial Union Insurance Co., a Massachusetts Corporation and Sandia Corporation, a New Mexico Corporation, D/B/A Sandia National Laboratories, United States of America, for the Use of Hugg Surveying Co., Plaintiff v. Western States Mechanical Contractors, Inc., a New Mexico Corporation and Commercial Union Insurance Co., a Massachusetts Corporation, Defendants- United States of America, for the Use of Hugg Surveying Co., Plaintiff v. Western States Mechanical Contractors, Inc., a New Mexico Corporation and Commercial Union Insurance Co., a Massachusetts Corporation, Defendants- the United States of America, for the Use of C.J.C., Inc., a New Mexico Corporation v. Western States Mechanical Contractors, Inc., a New Mexico Corporation and Commercial Union Insurance Co., a Massachusetts Corporation, Defendants- United States of America, for the Use of Fred Sanchez Construction Company v. Western States Mechanical Contractors, Inc., a New Mexico Corporation and Commercial Union Insurance Co., a Massachusetts Corporation, DefendantsCourt of Appeals for the Tenth Circuit · 1987
16 more not listed; retrieve them via the Exa API.