Clifford R. Gray, Inc. v. State
Appellate Division of the Supreme Court of the State of New York
1Opinion of the CourtCarpinello, J.
Appeals (1) from a judgment of the Court of Claims (King, J.), entered May 29, 1997, upon a decision of the court in favor of claimant, and (2) from an order of said court, entered September 19, 1997, which denied claimant’s motion to modify the judgment as inadequate.
*729Claimant was the prime electrical contractor on a project undertaken by the State Office of General Services (hereinafter OGS) for the construction of a mental health treatment unit at Great Meadow Correctional Facility in Washington County. The $1,125,800 contract was signed on July 30, 1990, with a proposed completion date of…
2Cases cited6 opinions
- Berley Industries, Inc. v. City of New YorkNew York Court of Appeals · 1978
- People v. BowmanNew York Court of Appeals · 1994
- Whitmyer Bros., Inc. v. StateNew York Court of Appeals · 1979
- Mid-State Precast Systems, Inc. v. Corbetta Construction Co.Appellate Division of the Supreme Court of the State of New York · 1994
- Yonkers Contracting Co. v. New York State Thruway AuthorityNew York Court of Appeals · 1969
1 more not listed; retrieve them via the Exa API.
3Cited by7 opinions
- United States Ex Rel. Maris Equipment Co. v. Morganti, Inc.District Court, E.D. New York · 2001
- Aniero Concrete Co. v. New York City Construction AuthorityDistrict Court, S.D. New York · 2003
- Crane-Hogan Structural System, Inc. v. StateAppellate Division of the Supreme Court of the State of New York · 2011
- Cruz v. Coastal Caisson, Corp.Court of Appeals for the Second Circuit · 2009
- E.W. Tompkins Co. v. StateAppellate Division of the Supreme Court of the State of New York · 2004
2 more not listed; retrieve them via the Exa API.