F & G Heating Co. v. Board of Education
Appellate Division of the Supreme Court of the State of New York
1Opinion of the Court
— In an action to recover damages for breach of a construction contract, plaintiff appeals from (1) an order and judgment (one paper) of the Supreme Court, Kings County (Gold-stein, J.), dated March 4, 1983, which granted the defendant board of education’s cross motion for partial summary judgment dismissing plaintiff’s claim for delay damages in the amount of $277,664.45 and (2) an order of the same court, dated July 21, 1983, which denied plaintiff’s motion, which was, in effect, to reargue defendant’s cross motion for partial summary judgment. H Order and judgment dated March 4, 1983,…
2Cases cited14 opinions
- Parochial Bus Systems, Inc. v. Board of EducationNew York Court of Appeals · 1983
- Foley v. RocheAppellate Division of the Supreme Court of the State of New York · 1979
- In re the Arbitration between the Board of Education & Wager Construction Corp.New York Court of Appeals · 1975
- Public Improvements, Inc. v. Board of EducationNew York Court of Appeals · 1982
- State Farm Mutual Automobile Insurance v. WernickAppellate Division of the Supreme Court of the State of New York · 1982
9 more not listed; retrieve them via the Exa API.
3Cited by14 opinions
- Pope v. Hempstead Union Free School District Board of EducationAppellate Division of the Supreme Court of the State of New York · 1993
- Kadish v. ColomboAppellate Division of the Supreme Court of the State of New York · 1986
- G.A. Contractors, Inc. v. Board of EducationAppellate Division of the Supreme Court of the State of New York · 1991
- McClellan v. Alexander Central School Board of EducationAppellate Division of the Supreme Court of the State of New York · 1994
- Schaefer v. Long Island RailroadAppellate Division of the Supreme Court of the State of New York · 1985
9 more not listed; retrieve them via the Exa API.